EPC合同条件(中英文对照版)

《EPC合同条件(中英文对照版)》由会员分享，可在线阅读，更多相关《EPC合同条件(中英文对照版)（106页珍藏版）》请在装配图网上搜索。

1、　　　　　　　　　　　　　　　　　　　　　　　　　　　　　　　　　 CONTENTS 目 录 1　General Provisions　一般规定 5 1.1　Definitions　定义 5 1.2　Interpretation　解释 10 1.3　Communications　通信交流 11 1.4　Law and Language　法律和语言 12 1.5　Priority of Document　文件优先次序 12 1.6　Contract Agreement　合同协议书 12 1.7　Assignment　权益转让 13 1.8　Care and Sup

2、ply of Document　文件的照管和提供 13 1.9　Confidentiality　保密性 14 1.10　Employer’s Use of Contractor’s Documents　雇主使用承包商文件 14 1.11　Contractor’s Use of Employer’s Documents　承包商使用雇主文件 15 1.12　Confidential Details　保密事项 15 1.13　Compliance with Laws　遵守法律 15 1.14　Joint and Several Liability　共同的和各自的责任 16 2　The

3、Employer　雇主 16 2.1　Right of Access to the Site　现场进入权 16 2.2　Permits, Licences or Approves　许可、执照或批准 17 2.3　Employer’s personnel　雇主人员 18 2.4　Employer’s Financial Arrangements　雇主的资金安排 18 2.5　Employer’s Claims　雇主的索赔 18 3　The Employer’s Administration　雇主的管理 19 3.1　The Employer’s Representative　雇主代

4、表 19 3.2　The Employer’s personnel　其他雇主人员 20 3.3　Delegated Persons　受托人员 20 3.4　Instructions　指示 21 3.5　Determinations　确定 21 4　The Contractor　承包商 21 4.1　The Contractor’s General Obligations　承包商的一般义务 22 4.2　Performance security　履约担保 22 4.3　Contractor’s Representative　承包商代表 23 4.4　Subcontractors

5、　分包商 24 4.5　Nominated Subcontractors　指定的分包商 25 4.6　Co-operation　合作 25 4.7　Setting out　放线 26 4.8　Safety procedures　安全程序 26 4.9　Quality Assurance　质量保证 27 4.10　Site Data　现场数据 27 4.11　Sufficiency of the Contract Price　合同价格 28 4.12　Unforeseeable Difficulties　不可预见的困难 28 4.13　Rights of way and Fac

6、ilities　道路通行权于设施 28 4.14　Avoidance of Interference　避免干扰 29 4.15　Access Route　进场通路 29 4.16　Transport of Goods　货物运输 30 4.17　Contractor’s Equipment　承包商设备 30 4.18　Protection of the Environment　环境保护 30 4.19　Electricity, Water and Gas　电、水和燃气 31 4.20　Employer’s Equipment and Free-Issue Material　雇主设备

7、和免费供应的材料 31 4.21　Progress Reports　进度报告 32 4.22　Security of the Site　现场保安 33 4.23　Contractor’s Operations on Site　承包商的现场作业 34 4.24　Fossils　化石 34 5　Design　设计 35 5.1　General Design Obligations　设计义务一般要求 35 5.2　Contractor’s Documents　承包商文件 36 5.3　Contractor’s Undertaking　承包商的承诺 37 5.4　Technical

8、Standards and Regulations　技术标准和法规 37 5.5　Training　培训 38 5.6　As-Built Documents　竣工文件 38 5.7　Operation and Maintenance Manuals　操作和维修手册 39 5.8　Design Error　设计错误 39 6　Staff and Labour　员工 39 6.1　Engagement of Staff and Labour　员工的雇用 40 6.2　Rates of Wages and Conditions of Labour　工资标准和劳动条件 40 6.3　P

9、ersons in the Service of Employer　为雇主服务的人员 40 6.4　Labour Laws　劳动法 40 6.5　Working Hours　工作时间 41 6.6　Facilities for Staff and Labour　为员工提供设施 41 6.7　Health and Safety　健康和安全 41 6.8　Contractor’s Superintendence　承包商的监督 42 6.9　Contractor’s Personnel　承包商人员 42 6.10　Records of contractor’s Personnel an

10、d Equipment　承包商人员和设备的记录 43 6.11　Disorderly Conduct　无序行为 43 7　Plant, Materials and Workmanship　生产设备、材料和工艺 43 7.1　Manner of Execution　实施方法 43 7.2　Samples　样品 44 7.3　Inspection　检验 44 7.4　Testing　试验 45 7.5　Rejection　拒收 46 7.6　Remedial Work　修补工作 46 7.7　Ownership of Plant and Materials　生产设备和材料的所有权

11、 47 7.8　Royalties　土地(矿区)使用费 47 8　Commencement,Delays and Suspension　开工、延误和暂停 48 8.1　Commencement of Works　工程的开工 48 8.2　Time for Completion　竣工时间 48 8.3　Programme　进度计划 49 8.4　Extension of Time for Completion　竣工时间延长 50 8.5　Delays Caused by Authorities　当局造成的延误 50 8.6　Rate of Progress　工程进度 51 8.

12、7　Delay Damages　误期损害赔偿费 51 8.8　Suspension of Work　暂时停工 52 8.9　Consequences of Suspension　暂停的后果 52 8.10　Payment for Plant and Materials in Event of Suspension　暂停时对生产设备和材料的付款 53 8.11　Prolonged Suspension　托长的暂停 53 8.12　Resumption of Work　复工 53 9　Tests on Completion　竣工试验　 54 9.1　Contractor’s Obli

13、gations　承包商的义务 54 9.2　Delayed Tests　延误的试验 55 9.3　Retesting　重新试验 55 9.4　Failure to Pass Tests on Completion　未能通过竣工试验 56 10　Employer’s Taking Over　雇主的接收　 56 10.1　Taking Over of the Works and Sections　工程和分项工程的接收 56 10.2　Taking Over of Parts of the Works　部分工程的接收 57 10.3　Interference with Tests on

14、 Completion　对竣工试验的干扰 57 11　Defects Liability　缺陷责任 58 11.1　Completion of Outstanding Work and Remedying Defects　完成扫尾工作和修补缺陷 58 11.2　Cost of Remedying Defects　修补缺陷的费用 59 11.3　Extension of Defects Notification Period　缺陷通知期的延长 59 11.4　Failure to Remedy Defects　未能修补的缺陷 60 11.5　Removal of Defective

15、Work　移出有缺陷的工程 60 11.6　Further Tests　进一步试验 61 11.7　Right of Access　进入权 61 11.8　Contractor to Search　承包商调查 61 11.9　Performance Certificate　履约证书 62 11.10　Unfulfilled Obligations　未履行的义务 62 11.11　Clearance of Site　现场清理 62 12　Tests after Completion　竣工后试验 63 12.1　Procedure for Tests after Completio

16、n　竣工后试验的程序 63 12.2　Delayed Tests　延误的试验 64 12.3　Retesting　重新试验 64 12.4　Failure to Pass Tests after Completion　未能通过的竣工后试验 65 13　Variations and Adjustments　变更和调整 66 13.1　Right to Vary　变更权 66 13.2　Value Engineering　价值工程 66 13.3　Variation Procedure　变更程序 66 13.4　Payment in Applicable Currencies　以适

17、用货币支付 67 13.5　Provisional Sums　暂列金额 67 13.6　Daywork　计日工作 68 13.7　Adjustments for Changes in Legislation　因法律改变的调整 69 13.8　Adjustments for Changes in Cost　因成本改变的调整 70 14　Contract price and Payment　合同价格和支付 70 14.1　The Contract Price　合同价格 70 14.2　Advance payment　预付款 70 14.3　Application for Inter

18、im Payments　期中付款的申请 72 14.4　Schedule of Payments　付款价格表 73 14.5　Plant and Materials intended for the Works　拟用于工程的生产设备和材料 73 14.6　Interim Payments　期中付款 74 14.7　Timing of Payments　付款的时间安排 74 14.8　Delayed Payment　延误的付款 75 14.9　Payment of Retention Money　保留金支付 75 14.10　Statement at Completion　施工报表

19、 76 14.11　Application for Final Payment　最终付款的申请 76 14.12　Discharge　结清证明 77 14.13　Final Payment　最终付款 77 14.14　Cessation of Employer’s Liability　雇主责任的中止 78 14.15　Currencies of Payment　支付的货币 78 15　Termination by Employer　由雇主终止 79 15.1　Notice to Correct　通知改正 79 15.2　Termination by Employer　由雇主终止

20、 79 15.3　Valuation at Date of Termination　终止日期时的估价 81 15.4　Payment after Termination　终止后的付款 81 15.5　Employer’s Entitlement to Termination　雇主终止的权利 82 16　Suspension and termination by Contractor由承包商暂停和终止 82 16.1　Contractor’s Entitlement to Suspend Work　承包商暂停工作的权利 82 16.2　Termination by Contracto

21、r　由承包商终止 83 16.3　Cessation of Work and Removal of Contractor’s Equipment　停止工作和承包商设备的撤离 84 16.4　Payment on Termination　终止时的付款 84 17　Risk and Responsibility　风险和职责 85 17.1　Indemnities　保障 85 17.2　Contractor’s Care of the Works　承包商对工程的照管 86 17.3　Employer’s Risks　雇主的风险 87 17.4　Consequence of Employ

22、er’s Risks　雇主风险的后果 87 17.5　Intellectual and Industrial Property Rights　知识产权和工业产权 88 17.6　Limitation of Liability　责任限度 89 18　Insurance　保险 89 18.1　General Requirements for Insurances　有关保险的一般要求 89 18.2　Insurance for Works and Contractor’s Equipment　工程和承包商设备的保险 91 18.3　Insurance against Injury to

23、Persons and Damage to Property　人身伤害和财产损害险 93 18.4　Insurance for Contractor’s Personnel　承包商人员的保险 94 19　Force Majeure　不可抗力　 94 19.1　Definition of Force Majeure　不可抗力的定义 95 19.2　Notice of Force Majeure　不可抗力的通知 96 19.3　Duty to Minimise Delay　将延误减至最小的义务 96 19.4　Consequences of Force Majeure　不可抗力的后果

24、96 19.5　Force Majeure Affecting Subcontractor　不可抗力影响分包商 97 19.6　Optional Termination, Payment and Release　自主选择终止、支付和解除 97 19.7　Release from Performance under the Law　根据法律解除履约 98 20　Claims, Disputes and Arbitration　索赔、争端和仲裁 98 20.1　Contractor’s Claims　承包商的索赔 99 20.2　Appointment of the Dispute A

25、djudication Board　争端裁决委员会的任命 100 20.3　Failure to Agreement Dispute Adjudication Board　对争端裁决委员会未能取得一致时 102 20.4　Obtaining Dispute Adjudication Board’s Decision　取得争端裁决委员会的决定 102 20.5　Amicable Settlement　友好解决 103 20.6　Arbitration　仲裁 104 20.7　Failure to Comply with Dispute Adjudication Board’s Deci

26、sion　未能遵守争端裁决委员会的决定 105 20.8　Expiry of Dispute Adjudication Board’s Appointment　争端裁决委员会任命期满 105 1　General Provisions 一般规定 1.1　Definitions 定义 In the Conditions of Contract (“these Conditions”), which include Particular Conditions and these General Conditions, the following words and expressi

27、ons shall have the meaning stated. Words indicating persons or parties include corporation and other legal entities, except where the context requires otherwise. 在合同条件（“本条件”），包括专用条件和通用条件中，下列词语和措辞应具有以下所述的含义.除上下文另有要求外，文中人员或当事各方等词语包括公司和其他合法实体. 1.1.1　The Contract consignee 合同 1.1.1.1　“Contract” mea

28、ns the Contract Agreement, these Conditions, the Employer’s Requirement, the Tender, and further document (if any) which are listed in the Contract Agreement. “合同”系指合同协议书、本条件、雇主要求、投标书和合同协议书列出的其他文件（如果有）. 1.1.1.2　“Contract Agreement” means the contract agreement referred to in Sub-Clause 1.6 [Contra

29、ct Agreement], including any annexed memoranda. “合同协议书”系指第1.6款[合同协议书]中所述的合同协议书及所附各项备忘录. 1.1.1.3　“Employer’s requirements” means the document entitled employer’s requirements, as included in the Contract, and any additions and modifications to such document in accordance with the Contract. Such doc

30、ument specifies the purpose, scope, and/or design and/or other technical criteria, for the Works. “雇主要求”系指合同中包括的，题为雇主要求的文件，其中列明工程的目标、范围、和（或）设计和（或）其他技术标准，以及按合同对此项文件所作的任何补充和修改. 1.1.1.4　“Tender” means the Contractor’s signed offer for the Works and all other documents which the Contractor submitted

31、therewith (other than these Conditions and Employer’s Requirements, if so submitted), as included in the Contract. “投标书”系指包含在合同中的由承包商提交的为完成工程签署的报价，以及随同提交的所有其他文件（本条件和雇主要求除外，如同时提交）. 1.1.1.5　“Performance Guarantees” and “Schedule of payments” mean the documents so named (if any), as included in the C

32、ontract. “履约保证”和“付款计划表”系指合同中包括的具有上述名称的文件（如果有）. 1.1.2　Parties and Persons 各方和人员 1.1.2.1　“Party” means the Employer or the Contractor, as the context requires. “当事方（或一方）”根据上下文需要，或指雇主，或指承包商。 1.1.2.1　“Employer” means the person named as employer in the Contract Agreement and the legal successors i

33、n title to this person. “雇主”系指在合同协议书中被称为雇主的当事人及其财产所有权的合法继承人。 1.1.2.3　“Contractor” means the person(s) named as contractor in the Contract Agreement and the legal successors in title to this person(s). “承包商”系指合同协议书中被称为承包商的当事人及其财产所有权的合法继承人。 1.1.2.4　“Employer’s Representative” means the person name

34、d by the Employer in the Contract or appointed from time to time by the Employer under Sub-Clause 3.1 [ the Employer’s Representative], who acts on behalf of the Employer. “雇主代表”系指由雇主在合同中指名的人员，或有时由雇主根据第3.1款［雇主代表的人员］的规定任命为其代表的人员。 1.1.2.5　“Contractor’s Representative” means the person named by the C

35、ontractor in the Contract or appointed from time to time by the Contractor Sub-Clause 4.3 [the Contractor’s Representative], who acts on behalf of the Contractor. “承包商代表”系指由承包商在合同中指名的人员，或有时由承包商根据第4.3款[承包商代表]的规定任命为其代表的人员。 1.1.2.6　“Employer’s Personnel” means the Employer’s Representative, the assis

36、tants referred to in Sub-Clause 3.2 [Other Employer’s Personnel] and all other staff, labour and other employees of the Employer and of the Employer’s Representative; and any other personnel notified to the Contractor, by the Employer or the Employer’s Representative, as Employer’s Personnel. “雇主人员

37、”系指雇主代表、第3.2款[其他雇主人员]中提到的助手、以及雇主和雇主代表的所有其他职员、工人和其他雇员，以及雇主或雇主代表通知承包商作为雇主人员的任何其他人员。 1.1.2.7　“Contractor’s Personnel” means the Contractor’s Representative and all personnel whom the Contractor utilizes on Site, who may include the staff, labour and other employees of the Contractor and of each Subcon

38、tractor, and any other personnel assisting the Contractor in the execution of the works. “承包商人员”系指承包商代表和承包商在现场聘用的所有人员，包括承包商和每个分包商的职员、工人和其他雇员，以及所有其他帮助承包商实施工程的人员。 1.1.2.8　“Subcontractor” means any person named in the Contract as a subcontractor, or any person appointed as a subcontractor, for a part

39、 of the Works; and the legal successors in title to each of these persons. “分包商”系指为完成部分工程，在合同中指名为分包商、或被任命为分包商的任何人员，以及这些人员财产所有权的合法继承人。 1.1.2.9　“DAB” means the person or three persons so named in the Contract, or other person(s) appointed under Sub-Clause 20.2 [Appointment of the Dispute Adjudicatio

40、n Board] or Sub-Clause 20.3 [Failure to Agree Dispute Adjudication Board]. “DAB（争端裁决委员会）”系指在合同中如此指名的一名或三名人员，或根据第20.2款[争端裁决委员会的任命]或第20.3款[对争端裁决委员会未能取得一致]的规定任命的其他人员。 1.1.2.10　“FIDIC” means the Federation International des Ingenieurs-Conseils, the international federation of consulting engineers. “

41、菲迪克（FIDIC）”系指国际咨询工程师联合会。 1.1.3　Dates ,Test, Periods and Completion 日期、试验、期限和竣工 1.1.3.1　“Base Date” means the date 28 days prior to the latest date for submission of the Tender. “基准日期”系指递交投标书截止前28天的日期。 1.1.3.2　“Commencement Date” means the date notified under Sub-Clause 8.1 [Commencement of Work

42、s], unless otherwise defined in the Contract Agreement. “开工日期”系指根据第8.1款[工程的开工]的规定通知的日期，合同协议书中另有规定的除外。 1.1.3.3　“Time for Completion” means the time for completing the Works or a Section (as the case may be) under Sub-Clause 8.2 [Time for Completion], as stated in the Particular Conditions (with any

43、 extension under Sub-Clause 8.4 [Execution of Time for Completion]), calculated from the Commencement Date. “竣工时间”系指专用条件中规定的，自开工日期算起，至工程或某分项工程（视情况而定）根据第8.2款[竣工时间]规定的要求竣工（连同根据第8.4款[竣工时间的延长]的规定提出的任何延长期）的全部时间。 1.1.3.4　“Tests on Completion” means the tests which are specified in the Contract or agree

44、d by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the works or a Section (as the case may be) are taken over by the Employer. “竣工试验”系指在合同中规定或双方商定的，或按指示作为一项变更的，在工程或某分项工程（视情况而定）被雇主接收前，根据第9条[竣工试验]的要求，进行的试验。 1.1.3.5　“Taking-Over Certi

45、ficate” means a certificate issued under Clause 10 [Employer’s Taking Over]. “接收证书”系指根据第10条[雇主接收]的规定颁发的证书。 1.1.3.6　“Tests after Completion” means the tests (if any) are specified in the Contract and which are carried out under Clause 12 [Tests after Completion] after the works or a Section (as th

46、e case may be) are taken over by the Employer. “竣工后试验”系指在合同中规定的，在工程或某分项工程（视情况而定）被雇主接收后，根据第12条[竣工后试验]的要求，进行的试验（如果有）。 1.1.3.7　“Defects Notification Period” means the period for notifying defects in the Works or a Section (as the case may be) under Sub-Clause 11.1 [Completion of Understanding Works a

47、nd Remedying Defects], as stated in the Particular Conditions (with any extension under Sub-Clause 11.3 [Extension of Defects Notification Period]), calculated from the date on which the Works or Section is competed as certified under Sub-Clause 10.1 [Taking Over of the Works and Sections]. If no su

48、ch period is stated in the Particular Conditions, the period shall be one year. “缺陷通知期限”系指专用条件中规定的，自工程或某分项工程（视情况而定）根据第10.1款[工程和分项工程的接收]的规定证明的竣工日期算起，至根据第11.1款[完成扫尾工作和修补缺陷]的规定通知工程或分项工程存在缺陷的期限（连同根据第11.3款[缺陷通知期限的延长]的规定提出的任何延长期）。如果专用条件中没有提出这一期限，该期限应为一年。 1.1.3.8　“Performance Certificate” means the certi

49、ficate issued under Sub-Clause 11.9 [Performance Certificate]. “履约证书”系指根据第11.9款[履约证书]的规定颁发的证书。 1.1.3.9　“day” means a calendar day and “year” means 365 days. “日（天）”系指一个日历日，“年”系指365天。 1.1.4　Money and Payments 款项与付款 1.1.4.1　“Contract Price” means the agreed amount stated in the Contract Agreement

50、 for the design, execution and completion of the Works and the remedying of any defects, and includes adjustment (if any) in accordance with the contract. “合同价格”系指在合同协议书中写明的、经商定的工程设计、施工、竣工和缺陷修补的款额，包括以及按照合同做出的调整（如果有）。 1.1.4.2　“Cost” means all expenditure reasonably incurred (or to be incurred) by t

51、he Contractor, whether on or off the Site, including overhead and similar charges, but does not include profit. “成本（费用）”系指承包商在现场内外所发生（或将发生）的所有合理开支，包括管理费用及类似的支出，但不包括利润。 1.1.4.3　“Final Statement” means the statement defined in Sub-Clause 14.11[Application for Final Payment]. “最终报表”系指第14.11款[最终付款的申请

52、]规定的报表。 1.1.4.4　“Foreign Currency” means a currency in which part (or all) of the Contract Price is payable, but not the Local Currency. “外币”系指可用于支付合同价格中部分（或全部）款项的当地货币以外的某种货币。 1.1.4.5　“Local Currency” means the currency of the Country. “当地货币”系指工程所在国的货币。 1.1.4.6　“Provisional Sum” means a sum (if

53、 any) which is specified in the Contract as a provisional sum, for the execution of any part of the Works or for the supply of Plant, Material or services under Sub-Clause 13.5 [Provisional Sums]. “暂列金额”系指合同中规定作为暂列金额的一笔款额（如果有），根据第13.5款[暂列金额]的规定，用于工程某一部分的实施，或用于提供生产设备、材料或服务。 1.1.4.7　“Retention Money

54、” means the accumulated retention moneys which the Employer retains under Sub-Clause 14.3 [Application for Interim Payments] and pays under Sub-Clause 14.9 [Payment of Retention Money]. “保留金”系指雇主根据第14.3款[期中付款的申请]的规定扣留的保留金累计金额，根据第14.9款[保留金的支付]的规定进行支付。 1.1.4.8　“Statement” means a statement submitted

55、 by the Contractor as part of an application for payment under Clause 14 [Contract Price and Payment]. “报表”系指承包商根据第14条[合同价格和付款]的规定提交的作为付款申请的组成部分的报表。 1.1.5　Works and Goods 工程和货物 1.1.5.1　“Contractor’s Equipment” means all apparatus, machinery, vehicles and other things required for the execution a

56、nd completion of the Works and remedying of any defects. However, Contractor’s Equipment excludes Temporary Works, Employer’s Equipment (if any), Plant, Materials and any other things intended to form or forming part of the Permanent Works. “承包商设备”系指为实施和完成工程、以及修补任何缺陷需要的所有仪器、机械、车辆和其他物品。但承包商设备不包括临时工程

57、、雇主设备（如果有）、以及拟构成或正构成永久工程一部分的生产设备、材料和其他任何物品。 1.1.5.2　“Goods” means Contractor’s Equipment, Materials, Plant and Temporary Works, or any of them as appropriate. “货物”系指承包商设备、材料、生产设备和临时工程，或视情况其中任何一种。 1.1.5.3　“Materials” means things of all kinds (other than Plant) intended to form or forming part of

58、the Permanent Works, including the supply-only materials (if any) to be supplied by the Contractor under the Contract. “材料”系指拟构成或正构成永久工程一部分的各类物品（生产设备除外），包括根据合同要由承包商供应的只供材料（如果有）。 1.1.5.4　“Permanent Works” means the permanent works to be designed and executed by the Contractor under the Contract. “

59、永久工程”系指根据合同承包商要进行设计和施工的永久性工程。 1.1.5.5　“Plant “means the apparatus, machinery and vehicles intended to form or forming part of the Permanent Works. “生产设备”系指拟构成或正构成永久工程一部分的仪器、机械和车辆。 1.1.5.6　“Section” means a part of the Works specified in the Particular Conditions as a Section (if any). “分项工程”系指在专

60、用条件中确定为分项工程（如果有）的工程组成部分。 1.1.5.7　“Temporary Works” means all temporary works of every kind (other than Contractor’s Equipment) required on Site for the execution and completion of the Permanent Works and the remedying of any defects. “临时工程”系指为实施和完成永久工程及修补任何缺陷，在现场所需的所有各类临时性工程（承包商设备除外）。 1.1.5.8　“Wo

61、rks” means the Permanent Works and the Temporary Works, or either of them as appropriate. “工程”系指永久工程和临时工程，或视情况指二者之一。 1.1.6　Other Definitions 其他定义 1.1.6.1　“Contractor’s Documents” means the calculations, computer programs and other software, drawings, manuals, models and other documents of a tech

62、nical nature supplied by the Contractor under the Contract; as described in Sub-Clause 5.2 [Contractor’s Documents]. “承包商文件”系指第5.2条款[承包商文件]中所述的，承包商根据合同应提交的所有计算书、 计算机程序和其他软件、图纸、手册、模型、以及其他技术性文件。 1.1.6.2　“Country” means the country in which the Site (or most of it) is located, where the Permanent Wor

63、ks are to be executed. “工程所在国”系指实施永久工程的现场（或其大部分）所在的国家。 1.1.6.3　“Employer’s Equipment” means the apparatus, machinery and vehicles (if any) made available by the Employer for the use of the Contractor in the execution of the Works, as stated in the Employer’s Requirements; but does not include Plan

64、t which has not been taken over by the Employer. “雇主设备”系指雇主要求中所述的，由雇主提供的供承包商在实施工程中使用的仪器、机械和车辆（如果有），但不包括尚未经雇主接收的生产设备。 1.1.6.4　“Fore Majeure” is defined in Clause 19 [Fore Majeure]. “不可抗力”见第19条[不可抗力]的定义。 1.1.6.5　“Laws” means all national (or state) legislation, statutes, ordinances and other laws,

65、 and regulations and by-laws of any legally constituted public authority. “法律”系指所有全国性（或洲的）法律、条例、法令和其他法律，以及任何合法建立的公共当局制定的规则和细则等。 1.1.1.6　“Performance Security” means the security (or securities, if any) under Sub-Clause 4.2 [Performance Security]. “履约担保”系指根据第4.2款[履约担保]规定的担保（或各项担保，如果有）。 1.1.6.7　“S

66、ite” means the places where the Permanent Works are to be executed and to which Plant and Materials are to be delivered, and any other places as may be specified in the Contract as forming part of the Site. “现场“系指将实施永久工程和运送生产设备与材料到达的地点，以及合同中可能指定为现场组成部分的任何其他场所。 1.1.6.8　“Variation” means any change to the Employer’s Requirements or the Works, which is instructed or approved as a variation under Clause 13 [Variation and Adjustment]. “变更”系指按照第13条[变更和调整]的规定，经指示或批准作为变更的，对雇主要求或工程所做的任何更改。 1.2　Interp